Terms and Conditions
Welcome to Desert Sun Systems! By accessing our website or engaging with our services, you agree to the following terms and conditions. Please read them carefully before using our services or submitting a request for a quote.
---
1. Value-Added Reseller Disclosure
Desert Sun Systems operates as a value-added reseller of the products and services mentioned on our website. We partner with trusted third-party providers and contractors to deliver these products and services to our customers.
---
2. Quote Requests and Communications
By requesting a quote through our website, phone, or email:
- You consent to being contacted by Desert Sun Systems and our affiliate partners via phone, text message, and/or email for communication related to your inquiry or ongoing services.
- You have the right to opt out of communications at any time by notifying us directly.
---
3. Independent Contractors
Desert Sun Systems collaborates with independent contractors to deliver certain services. While we strive to partner with reputable contractors, Desert Sun Systems:
- Does not directly perform the contracted services.
- Is not responsible for any damage, loss, or liability caused to your property or arising from the actions of independent contractors.
---
4. Limitation of Liability
To the fullest extent permitted by law, Desert Sun Systems:
- Will not be held liable for any direct, indirect, incidental, or consequential damages arising from the use of products or services provided by independent contractors.
- Is not responsible for delays or service failures resulting from events outside of our control, including but not limited to weather, labor shortages, or supply chain disruptions.
---
5. Warranties
All product warranties, if applicable, are provided by the manufacturer or service provider. Desert Sun Systems does not offer any additional warranties beyond those stated by the original manufacturer or provider.
---
6. Payment Terms
Payment terms, including deposits and final balances, will be outlined in the agreements provided at the time of service. Failure to meet payment obligations may result in delays, penalties, or cancellation of services.
---
7. Arbitration Agreement
In the event of a dispute arising from or relating to these terms, both parties agree to resolve the matter through binding arbitration in the State of Arizona. Arbitration shall be conducted in accordance with the rules of the American Arbitration Association (AAA). Each party will bear its own costs for the arbitration unless otherwise determined by the arbitrator.
---
8. Governing Law
These terms and conditions shall be governed by and construed in accordance with the laws of the State of Arizona.
---
9. Privacy Policy
Your privacy is important to us. Any personal information collected is used solely for the purpose of providing services and will not be shared with third parties except as necessary to fulfill your requests.
---
10. Amendments
Desert Sun Systems reserves the right to update or modify these terms and conditions at any time without prior notice. Changes will be posted on our website, and continued use of our services signifies your acceptance of the revised terms.
---
Contact
If you have any questions regarding these terms and conditions, please contact us.
---
By using our website or engaging our services, you acknowledge and agree to the above terms and conditions.